Construction Contract Basics: No Damages for Delay
May 06, 2024 —
Christopher G. Hill - Construction Law MusingsAfter WAY too long a hiatus, I am back with another in my series of “Construction Contract Basics” posts. In past posts, I’ve covered venue provisions, attorney fee provisions, and indemnity clauses. In this post, I’ll share a few thoughts (or “musings”) on the topic of so-called “no damages for delay” clauses. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the owner or general contractor, is an extension of time to complete the work.
These types of clauses generally make it impossible for a subcontractor (if found in a Subcontract) or Contractor (if found in a Prime Contract) that is delayed through no fault of its own to recover any damages relating to the expenses that are inevitably caused by such delays. Such expenses/damages could include additional supervisory time (including more high-dollar superintendent payments), acceleration costs, demobilization/mobilization costs, and other related expenses. These can add up to real money. Couple that with the inevitable liquidated damages or delay damages that will occur should a contractor or subcontractor cause any delay, and this becomes a very one-sided proposition.
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
'Taylor Swift Is an Economic Phenomenon': CE's Q1 2024 Economic Update and Forecast
April 29, 2024 —
Grace Calengor - Construction ExecutiveOn March 27, Construction Executive presented its "2024 Q1 Economic Update and Forecast," hosted by ABC Chief Economist Anirban Basu. If you've attended previous versions of this webinar, you're familiar with Basu’s pragmatic approach to the economics of the construction industry and his penchant for predicting recession. But this quarter, he opted for an almost-optimistic approach and hinted at walking back his thoughts on recession. Read the most quotable moments, new poll results and top takeaways from the presentation below.
POLL RESULTS: Q1 2024 vs. Q4 2023 Poll 1: Which of these is the leading challenge for your company today?
Supply chain and/or materials issues
Skills/worker shortage
Insufficient demand for construction services
Availability of financing for projects/project work
None of the above
December 2023 | March 2024 |
10% |
7% |
57% |
60% |
11% |
11% |
19% |
17% |
3% |
6% |
Reprinted courtesy of Grace Calengor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Hawaii Court of Appeals Finds Insured AOAO Not Liable for Securing Inadequate Insurance
March 04, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe Hawaii Intermediate Court of Appeals (ICA) affirmed the trial court's finding that the insured Association of Apartment Owners (AOAO) was not liable for securing a policy with inadequate coverage. AOAO Queen Emma Gardens, et al v. Wa, 2023 Haw. App. LEXIS 400 (Haw. Ct. App. Dec. 19, 2023).
In October 2002, the Was purchased a condominium located in the Queen Emma Gardens Condominium. The AOAO's bylaws provided that it would procure and maintain insurance "to insure the Board, the Association, and each apartment owner against claims for personal injury, death, and property damage arising out of the condition of the property or activities thereon . . ." The AOAO secured a CGL policy from Insurance Association, Inc., with coverage limits for bodily injury at $1,000,000 and an umbrella policy providing an additional $5,000,000 of coverage. Each of the policies "insured each individual insurance owner of the insured condominium, but only with respect to liability arising out of the ownership, maintenance or repair of that portion of the premises which is not reserved for that unit owner's exclusive use or occupancy."
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Court Finds Matching of Damaged Materials is Required by Policy
April 02, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe court granted, in part, the insured's motion for summary judgment by finding that matching roof tiles were required under the policy. Bertisen v. Travelers Home and Marine Ins. Co., 2024 U.S. Dist. LEXIS 3907 (D. Colo. Jan. 8, 2024).
The insureds sued Travelers for breach of contract, common law bad faith, and unreasonable delay or denial of benefits. They alleged that their residence was damaged by a hailstorm and that Travelers breached their policy and acted in bad faith in the handling of the claim. The insureds demanded an appraisal to determine the "amount of loss" under the policy and an appraisal award was issued. Travelers then denied payment for all roof tiles that were contemplated by the appraisal award.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Sarah P. Long Expands Insurance Coverage Team at Payne & Fears
March 19, 2024 —
Payne & Fears LLPSarah P. Long has joined Payne & Fears LLP as a Partner in the firm’s Insurance Coverage and Litigation Group. Sarah has represented clients in all aspects of insurance coverage and litigation and also focus on construction defect claims and litigation.
Before joining Payne & Fears, Sarah was a partner at Koeller, Nebeker, Carlson, Haluck, LLP, where she represented many of the nation’s builders in construction defect actions and bad faith insurance coverage disputes for 17 years.
Known for her dependability, efficiency, and creative problem-solving, Sarah always strives to secure the best results for her clients in the most efficient manner.
“We are excited to welcome Sarah to P&F as we continue to expand and add depth to our Insurance Litigation Group. I have known Sarah in a professional and personal capacity for more than 16 years. She is well respected by clients and peers in the legal profession. She is a bright, efficient, and innovative attorney and a wonderful person,” said Sarah Odia, the group’s co-chair.
Read the full story...Reprinted courtesy of
Payne & Fears LLP
Meet the Forum's In-House Counsel: KATE GOLDEN
February 19, 2024 —
Jessica Knox - The Dispute ResolverCompany: Mortenson
Email: kate.golden@mortenson.com
Website: www.mortenson.com
College: University of Iowa (Bachelor of Science in Engineering, 1991)
Graduate School: University of Minnesota (Master of Science in Civil Engineering, 1994)
Law School: William Mitchell College of Law (now Mitchell | Hamline School of Law) (JD 1999)
States Where Company Operates/Does Business: Mortenson is a national builder and developer with 13 regional office locations.
Q: Describe your background and the path you took to becoming in-house counsel.
A: In high school, I loved math and science, so I attended the University of Iowa College of Engineering and studied civil engineering, with a focus on environmental engineering. To practice environmental engineering at that time, you generally needed a master’s degree, so I attended the University of Minnesota, where my thesis for my degree program was “Organochlorines in Lake Michigan.” I then worked as an environmental engineer for a consulting firm called Montgomery Watson (now MWH) assisting clients with various environmental issues from air permitting to watershed reports to risk assessments of contaminated sites.
Read the full story...Reprinted courtesy of
Jessica Knox, Stinson LLPMs. Knox may be contacted at
jessica.knox@stinson.com
Traub Lieberman Attorneys Lisa M. Rolle, Eric D. Suben, and Justyn Verzillo Secure Dismissal of All Claims in a Premises Liability Case
November 16, 2023 —
Lisa M. Rolle, Eric D. Suben & Justyn Verzillo - Traub LiebermanOn an appeal of an order denying Defendant’s motion to dismiss the complaint in a slip-and-fall action commenced in Kings County Supreme Court, Traub Lieberman attorneys Lisa M. Rolle, Eric D. Suben, and Justyn Verzillo successfully secured dismissal of all claims by the Appellate Division, Second Department, on behalf of Traub Lieberman’s client.
The lawsuit sought to recover damages arising out of injuries the Plaintiff allegedly sustained when she slipped and fell in the shower of a rental property owned by the Defendant, a limited liability company. Plaintiff alleged that the subject shower was defective, and the Defendant negligent, based on the absence of non-slip surfacing and grab bars in the shower. Aside from premises liability (negligence), Plaintiffs asserted eight other causes of action, including gross negligence, breach of warranty of habitability, intentional infliction of emotional distress, negligent infliction of emotional distress, alter-ego liability, loss of consortium, and for declaratory judgment.
The judge in Supreme Court denied Traub Lieberman’s motion to dismiss on behalf of Defendant, citing as the sole reason that the affidavits submitted with the motion were unsigned, and ignoring Traub Lieberman’s arguments pointing out the glaring facial deficiencies of Plaintiff’s pleading and that the signed affidavits were in fact submitted before the return date.
Reprinted courtesy of
Lisa M. Rolle, Traub Lieberman,
Eric D. Suben, Traub Lieberman and
Justyn Verzillo, Traub Lieberman
Ms. Rolle may be contacted at lrolle@tlsslaw.com
Mr. Suben may be contacted at esuben@tlsslaw.com
Mr. Verzillo may be contacted at jverzillo@tlsslaw.com
Read the full story...
Orange County Team Obtains Unanimous Defense Verdict in Case Involving Failed Real Estate Transaction
March 25, 2024 —
Lewis Brisbois NewsroomOrange County, Calif. (March 4, 2024) - Orange County Partners Esther P. Holm and Alexandra Anast obtained a unanimous defense verdict in a real estate matter involving a failed real estate transaction. The property at issue, which was located in the West Hollywood Hills and had beautiful views, was undergoing extensive remodeling. There were several bids for its purchase. Ultimately, the plaintiff, a real estate investor, was awarded the purchase.
The plaintiff and the seller entered into a real estate purchase agreement, but the plaintiff failed to release the physical contingencies within the 17-day period prescribed by the contract. Instead, the plaintiff demanded a reduction in price, which the seller rejected. The plaintiff then filed a lis pendens on the property, clouding the title and making it impossible for the sellers to sell the property to anyone else. The buyer and seller subsequently engaged counsel. The plaintiff filed the lawsuit against the seller as well as the real estate company and its agents. Prior to trial, the plaintiff and the seller reached a settlement.
Read the full story...Reprinted courtesy of
Lewis Brisbois