Enforceability of Contract Provisions Extending Liquidated Damages Beyond Substantial Completion
April 15, 2024 —
Stu Richeson - The Dispute ResolverThis post takes a look at the enforceability of contract provisions providing for liquidated delay damages after substantial completion. Typically, the assessment of liquidated delay damages ends at substantial completion of a project. However, various standard form contracts, including some of the ConsensusDocs and EJCDC contracts, contain elections allowing for the parties to agree on the use of liquidated damages for failing to achieve substantial completion, final completion, or project milestones. The standard language in the AIA A201 leaves it up to the parties to define the circumstances under which liquidated damages will be awarded.
Courts are split on the enforceability of provisions that seek to assess liquidated damages beyond substantial completions. Courts in some jurisdictions will not impose liquidated damages after the date of substantial completion on the ground that liquidated damages would otherwise become a penalty if assessed after the owner has put the project to its intended use. Perini Corp. v. Greate Bay Hotel & Casino, Inc., 129 N.J. 479, 610 A.2d 364 (1992). When the terms are clear, other jurisdictions will enforce contract terms providing for liquidated damages until final completion, even if the owner has taken beneficial use of the facility. Carrothers Const. Co. v. City of S. Hutchinson, 288 Kan. 743, 207 P.3d 231 (2009).
Read the full story...Reprinted courtesy of
Stu Richeson, PhelpsMr. Richeson may be contacted at
stuart.richeson@phelps.com
Construction Litigation Roundup: “You Have No Class(ification)”
May 13, 2024 —
Daniel Lund III - LexologyIn fact, you didn’t even have a license.
A federal court in Alabama was tasked with determining whether an unlicensed contractor could recover from an Alabama project owner for in excess of $1.7 million in construction infrastructure and site work performed. In fact, the contractor “did not have a valid general contractor’s license” in the state of Alabama when it “assumed work on the project from its predecessor company.”
During the course of work on the project, the principals of an original contractor decided to go their separate ways, whereupon one of those principals announced that his new company would take over ongoing work. Roughly two months after the new company began working at the project, the contractor applied for a license with the Alabama Licensing Board of General Contractors – the license was issued within about 45 days. Then, some eight months later, the contractor added a “municipal and utilities” classification to its contractor license.
Read the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
Evaluating Construction Trends From 2023 and Forecasting For 2024
February 12, 2024 —
Jason Feld & Dominic Donato - Kahana FeldAs we begin 2024, it is informative to evaluate what transpired in 2023 in the construction industry, and especially the use of construction technology. 2023 ushered in a variety of newly implemented construction technologies including 3D printed entire houses, improved wearables that detect all aspects of the construction worker from location to temperature to heart rate, increased use of modular construction for entire apartments, hotels, and condominium projects, and eco-friendly and conservation minded technologies to minimize carbon footprint, water preservation and sustainable construction methods, to name a few.
2023 also identified some significant issues in the construction industry. First and foremost, the labor shortages and hiring of skilled and qualified workers continued to be an issue resulting in increased delays, construction accidents, and project mismanagement. The skyrocketing interest rates, decline in commercial/office projects, supply chain issues, material price fluctuation and increase changes in scope of projects all negatively impacted the construction industry in 2023. There is also the demand for renewable and infrastructure projects put strain on construction resources as the projects became “mega” with larger and more complex construction leading to multi-party, high dollar, and more complex claims. Finally, there is a growing trend of construction claims and litigation being financed by third party litigation funding sources for personal/bodily injury claims and construction defect claims.
Reprinted courtesy of
Jason Feld, Kahana Feld and
Dominic Donato, Kahana Feld
Mr. Feld may be contacted at jfeld@kahanafeld.com
Mr. Donato may be contacted at ddonato@kahanafeld.com
Read the full story...
Appraisal Panel Can Determine Causation of Loss under Ohio Law
February 19, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court granted the insured's motion to compel an appraisal that would include a determination of causation of the loss. Eagle Highland Owners Association v. State Farm Fire and Casualty Co., 2023 U.S. Dist. LEXIS 220937 (S.D. Ohio Dec. 12, 2023).
Plaintiff argued its property suffered wind and hail damage from a storm on June 18, 2021. A claim was submitted to State Farm. State Farm's investigation determined the loss to be $0.00. Plaintiff's investigator determined the loss to be $586,647.08 in repair costs.
State Farm opposed appraisal because, in its view, the damage arose from a loss in 2019, not from the June 18, 2021 storm. Plaintiff submitted a loss claim in 2019 for damage that State Farm alleged was exactly the same as the damage alleged in the loss claim for the June 18, 2021 storm. Therefore, State Farm did not view the matter as a dispute over an amount of loss, but rather over whether a loss even occurred on June 18, 2021.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Mechanic’s Liens- Big Exception
January 22, 2024 —
Christopher G. Hill - Construction Law MusingsMusings has discussed mechanic’s liens on
numerous occasions.
As we discussed in earlier posts, the general rule is that a
mechanic’s lien jumps to the head of the line of liens when filed. This is true in most instances. In the typical case, a contractor puts up a building and, when the owner refuses payment, it files a mechanic’s lien that takes priority over all other liens on that property, including the construction loan
deed of trust (or
mortgage, depending on your state’s property laws).
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Court Grants Insurer's Motion for Summary Judgment After Insured Fails to Provide Evidence of Systemic Collapse
April 15, 2024 —
Tred R. Eyerly - Insurance Law HawaiiWith the insurer conceding that there was evidence of potential collapse at portions of eight specific building locations, the court granted the insurer's motion for partial summary judgment in determining no additional buildings suffered from collapse. Exec. 1801 LLC v. Eagle W. Ins. Co., 2024 U.S. Dist. LEZXIS 5923 (D. Or. Jan. 11, 2024).
Executive 1801 owned a group of six buildings with eighty-six residential units. The court previously granted partial summary judgment on Executive 1801's rain damage claim, leaving only claims regarding collapse. Eagle insured "the property for direct physical los or damage to Covered Property . . . caused by or resulting from any Covered Cause of loss." The policy further provided, "We will pay for direct physical loss or damage to Covered Property, caused by collapse of a building or any part of a building insured under this policy, if the collapse is caused by . . . hidden decay."
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Insurance Litigation Roundup: “Post No Bills!”
April 02, 2024 —
Daniel Lund III - LexologyA company which is in the business of posting “advertising signs on temporary construction sites on behalf of clients” was “sued for trespass, conversion, and other torts” when it entered a site to remove posters. The company sought to have its insurance carrier cover the cost of its defense but was refused. A federal court lawsuit in California against the insurer ensued. The insurer prevailed on a Rule 12 motion to dismiss, and the insured appealed.
At issue: had an “occurrence” under the CGL policy taken place – that is, an “accident,” an “unexpected, unforeseen, or undesigned happening or consequence from either a known or unknown cause?” The appellate court noted that the company’s contractor “intended” to enter the work site and remove posters, which gave rise to the trespass claim. For its part, the company urged that the contractor’s actions “were based on erroneous information… [a] mistaken belief that it had the right or duty to enter the site and remove the posters….”
Read the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
Construction Litigation Roundup: “Wrap Music to an Insurer’s Ears?”
February 05, 2024 —
Daniel Lund III - LexologyThe general contractor on a New Orleans condominium construction project obtained a Contractor Controlled Insurance Program/CCIP policy or "Wrap-Up" policy for the job.
An accident occurred on the job when a construction elevator/hoist fell, injuring several workers. The elevator/hoist was provided by a subcontractor, pursuant to a rental agreement and related subcontract with the general contractor. Contained within the subcontract was a provision which states that the general contractor "has arranged for the Project to be insured under a controlled insurance program (the "CCIP" or "WrapUp"),” and that the CCIP shall provide "commercial general liability insurance and excess liability insurance, in connection with the performance of the Work at the Project site."
A third-party administrator for the wrap-up policy had been in communication with the subcontractor prior to the commencement of the work, “specifically advising that insurance coverage was not automatic” and providing the subcontractor with an enrollment form for the CCIP. Ultimately, the subcontractor “declined to comply with the request,” stating that the subcontractor would "not participate in paying any wrap insurance premiums" – because the subcontractor had its own insurance.
Read the full story...Reprinted courtesy of
Owners Should Serve Request for Sworn Statement of Account on LienorShort on Labor, Israeli Builders Seek to Vaccinate PalestiniansCoverage Found For Cleanup of Superfund Site Despite Pollution ExclusionCalifornia Supreme Court Upholds Precondemnation ProceduresWhy Federal and State Agencies are Considering Converting from a “Gallons Consumed” to a “Road Usage” Tax – And What are the Risks to the Consumer?Your Work Exclusion Applies to Damage to Tradesman's Property, Not Damage to Other PropertyAttorney Risks Disqualification If After Receiving Presumptively Privileged Communication Fails to Notify Privilege Holder and Uses Document Pending Privilege Determination by CourtDenver Airport Terminates P3 Contract For Main Terminal RenovationHomeowner Loses Suit against Architect and Contractor of Resold HomeConstruction Delays for China’s Bahamas Resort ProjectLewis Brisbois Ranked Tier 1 Nationally for Insurance Law, Mass Tort/Class Actions Defense by U.S. News/Best LawyersArchitect Sues over Bidding ProcedureDC Circuit Approves, with Some Misgivings, FERC’s Approval of the Atlantic Sunrise Natural Gas Pipeline ExtensionBHA has a Nice Swing Benefits the Wounded Warrior ProjectAllegations Versus “True Facts”: Which Govern the Duty to Defend? Bonus! A Georgia Court Clears Up What the Meaning of “Is” IsA Court-Side Seat: Appeals and Agency Developments at the Close of 2020Eminent Domain Bomb Threats Made on $775M Alabama Highway ProjectYellen Has Scant Power to Relieve U.S. Housing SlowdownFederal Public Works Construction Collection Remedies: The Miller Act Payment Bond ClaimInsurer Sued for Altering Policies after ClaimConstruction Materials Company CEO Sees Upturn in Building, Leading to JobsImportant Environmental Insurance Ruling Issued In Protracted Insurance-Coverage DisputeHunton Insurance Partner Among Top 250 Women in LitigationFlorida Supreme Court Adopts Federal Summary Judgment Standard, Substantially Conforming Florida’s Rule 1.510 to Federal Rule 56Sacramento Water Works Recognized as a Historic Civil Engineering LandmarkAxa Unveils Plans to Transform ‘Stump’ Into London SkyscraperConsumer Prices Rising as U.S. Housing Stabilizes: EconomyAt $350 Million, Beverly Hillbillies Mansion Is Most Expensive in U.S.Construction and Contract Issues Blamed for Problems at Anchorage PortCity Potentially Liable for Cost Overrun on Not-to-Exceed Public Works ContractWhen Is an Arbitration Clause Unconscionable? Not OftenFlag on the Play! Expired Contractor’s License!The Role of Code Officials in the Design-Build ProcessUnderstand and Define Key Substantive Contract ProvisionsFederal Court Predicts Coverage In Utah for Damage Caused By Faulty WorkmanshipQuick Note: Insurer’s Denial of Coverage Waives Right to Enforce Post-Loss Policy ConditionsInsurer's Quote on Coverage for Theft by Hacker Creates Issue of FactGloria Gaynor Sues Contractor over Defective Deck ConstructionWall Failure Due to Construction Defect Says InsurerAmazon Can be Held Strictly Liable as a Product Seller in New JerseyCondominium Association Wins $5 Million Judgment against DeveloperCongress Relaxes Several PPP Loan RequirementsCourt Slams the Privette Door on Independent Contractor’s Bodily Injury ClaimUPDATE - McMillin Albany LLC v. Superior CourtMultisensory Marvel: Exploring the Innovative MSG SphereNarberth Mayor Urges Dubious Legal ActionLegislative Update: Bid Protest Law Changes to Benefit ContractorsProperty Insurance Exclusion for Constant or Repeated Leakage of WaterYet Another Reminder that Tort and Contract Don’t MixSafety Accusations Fly in Dispute Between New York Developer and Contractor