PLASTER EXPERT WITNESS FORENSIC ARCHITECT EXPERT WITNESS BALDWIN FLORIDA FLORIDA FLORIDA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Understanding Entitlement to Delays and Proper Support

December 10, 2024 — Andrew G. Vicknair - The Dispute Resolver
In a previous post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method. Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay. If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Newport Beach Attorneys John Toohey and Nick Rodriguez Receive Full Defense Verdict

July 31, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara is pleased to report that Partner John Toohey and Senior Associate Nicholas Rodriguez received a complete defense verdict after a 5-week jury trial in Orange County Superior Court. The case involved a multimillion-dollar home in Orange County. Plaintiff had originally suffered a water loss throughout areas of the home. Our client, an Orange County restoration and construction company, was hired to provide on-going estimates and perform demolition. Plaintiff claimed that, in the course of the demolition process, asbestos containing material was disturbed and spread resulting in contamination throughout home. Plaintiff claimed contractor negligence and breach of contract against our client. Plaintiff sought millions against our client in general and special damages for whole home restoration and other related general damages. The jury found in complete favor of our client on all allegations and awarded zero dollars to the opposing party. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Wildfire Threats Make Utilities Uninsurable in US West

August 12, 2024 — Mark Chediak - Bloomberg
Trinity Public Utilities District’s power lines snake through the lower reaches of the Cascade Range, a rugged, remote and densely forested terrain in Northern California that has some of the highest wildfire risk in the country. But for several years, the company has been without insurance to protect it from such a threat. Trinity’s equipment was blamed for causing a 2017 wildfire that destroyed 72 homes and three years later its insurer, a California public agency called the Special District Risk Management Authority, told the utility that it would no longer cover it for fires started by its electrical lines. Trinity could find no other takers. The utility’s exposure comes as wildfires are already flaring up across the US West in what could be a dangerous and prolonged fire season. “If a fire were to start now that involved one of our power lines, it would likely bankrupt the utility,” said Paul Hauser, general manager of the local government-owned utility that serves about 13,000 rural customers in Trinity County, 200 miles (322 kilometers) north of Sacramento. That’s because without insurance, a lawsuit could put the utility on the hook to pay for damages to private homes and businesses, which could easily top the utility’s annual revenue of about $16 million. Read the full story...
Reprinted courtesy of Mark Chediak, Bloomberg

---

Ethical Limits on Preparing a Witness for Deposition or Trial

October 28, 2024 — Stu Richeson - The Dispute Resolver
In this week’s blog post, we are going to take a brief look at ethical issues associated with preparing a witness for a deposition or to testify at trial. Most attorneys would agree that it is permissible to meet with a witness before the witness’s deposition to discuss what to expect. On the other hand, there is no question that advising a witness to provide false testimony would be improper. But what about the area in between those two extremes? For instance, can an attorney suggest to a witness how to phrase answers to anticipated questions that, while true, might not be the way the witness would have answered the question absent the attorney’s coaching? A little over a year ago, the American Bar Association Standing Committee on Ethics and Professional Responsibility issued ABA Formal Opinion 508: The Ethics of Witness Preparation. The opinion provides certain examples of things that are and are not permissible in preparing a witness for a deposition or trial. Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

---

Appetite for Deconstruction

July 02, 2024 — Patrick Sisson - Bloomberg
The death of 206 College Avenue was slow and painstaking. Over several days in January 2022, dozens of bundled-up volunteers swarmed over the three-story property, a tired wooden boarding house built in the early 1900s in Ithaca, New York. Long used as rental apartments for Cornell University students, the 13-bedroom house was set to be demolished, along with several neighboring structures of the same vintage, to make room for a new multi-use complex. But while those buildings were quickly reduced to rubble by trackhoes, the house at 206 was deconstructed, piece by piece, so that its elements could be used again. The Catherine Commons Deconstruction Project, an effort by Cornell’s Circular Construction Lab, was a large-scale pilot designed to show how building waste can be kept out of landfills. As volunteers pulled nails out of fir, oak, and walnut boards and hauled lumber off to be sorted and redistributed, a team of eight workers with heavy machinery began meticulously sawing, slicing and removing 8-by-18-foot panels of the old building. These were trucked off to a warehouse, where they’d be taken apart and recycled. The labor that went into this process was substantially more than a typical demolition. But it avoided the societal penalties left behind at nearly every building and demo site across the US. The sheer volume of waste generated by knocking down, adding to or renovating buildings in the US is stunning: 600 million tons of construction demolition waste annually, according to the most recent EPA estimate from 2018. Roughly 75% gets ground up into aggregate and fill, and only a small share is recycled and reused, necessitating production of new material for the next project. For scale, municipal solid waste only accounts for 300 million tons every year. Read the full story...
Reprinted courtesy of Patrick Sisson, Bloomberg

---

Insurer Waives Objection to Appraiser's Partiality by Waiting Until Appraisal Issued

October 21, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Eleventh Circuit affirmed the district court's denial of the insurer's objections on partiality grounds to the insured's appraiser. Biscayne Beach Club Condominium Association, Inc. v. Westchester Surpus Lines Ins. Co., 2024 U.S. App. LEXIS 19663 (11th Cir. Aug. 6. 2024). Storms damaged buildings at Biscayne Beach Club Condominium. Biscayne Beach filed claims with its insurer, Westchester. Unsatisfied with Westchester's payments, Biscayne Beach sued. Westchester then invoked the appraisal provision in the policy. The district court abated the action so the parties could pursue appraisal. Biscayne Beach appointed Lester Martin, its public adjuster, as its appraiser on a 10 percent contingency fee. Westchester objected because Martinez's retainer created a conflict of interest that would hinder his impartiality. Biscayne Beach then retained Blake Pyka as its appraiser. Westchester appointed its appraiser and and umpire was selected by the parties' two appraisers. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

There is No Claims File Privilege in Florida, Despite What Insurers Want You to Think

June 17, 2024 — Susana Arce & Stephanie A. Giagnorio - Saxe Doernberger & Vita, P.C.
As Florida insurers continue their attempts to narrow protections for policyholders, it is imperative - now more than ever - that insureds be well-informed and know their rights. Most recently, in Florida, insurers are attempting to weaponize the death of Senate Bill 1726 and House Bill 1287 to limit the documents disclosed to policyholders. Specifically, the proposed bill, which required insurers to disclose their claims file to policyholders, hoped to thwart insurers from utilizing “claims file privilege” to obstruct justice for policyholders and help level the playing field. The goal of the proposed bill was to promote transparency of the claim adjustment process and undercut insurers’ attempts to dodge discovery of relevant and necessary information during litigation, forcing the insurers to fully and honestly justify their basis for withholding coverage . Unfortunately for policyholders, on March 8, 2024, the proposed legislation was not passed by the Insurance and Banking Subcommittee. While insurers want you to believe this is a significant victory and a free pass to continue withholding documents under a “claims file privilege,” this is not the case. The proposed bill merely codified current Florida law – simply put, the “claims file privilege” never existed, and still does not. Reprinted courtesy of Susana Arce, Saxe Doernberger & Vita, P.C. and Stephanie A. Giagnorio, Saxe Doernberger & Vita, P.C. Ms. Arce may be contacted at SArce@sdvlaw.com Ms. Giagnorio may be contacted at SGiagnorio@sdvlaw.com Read the full story...

---

Toolbox Talk Series Recap - Undocumented Change Work

October 15, 2024 — Douglas J. Mackin - The Dispute Resolver
In the August 29, 2024 edition of Division 1's Toolbox Talk Series, Don Rea presented on the causes of undocumented change order work and what actions parties to a construction project can take to protect themselves, which compliments and reinforces some of the key points from the May 30, 2024 Toolbox Talk on maximizing profits while experiencing changes during project performance. Article 7 of AIA A201 General Conditions covers (i) change orders, (ii) constructive change directives, and (iii) “minor changes.” Work that falls outside the scope of the construction contract will often fit into one of these three categories. Rea’s presentation focused on the fact that, regardless of which category applies, proper documentation of the change work is vital. Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

---