Denial of Motion to Dissolve Lis Pendens Does Not Automatically Create Basis for Certiorari Relief
November 16, 2023 —
David Adelstein - Florida Construction Legal UpdatesA recent appellate decision out of Florida’s Sixth District Court of Appeal holds that a trial court’s denial of motion to dissolve a lis pendens does NOT automatically give a basis for a petition for a writ of certiorari. Generalized allegations of “irreparable harm” to support the basis for the petition for writ of certiorari are insufficient. Rather, the party moving for the petition MUST clearly demonstrate the irreparable harm; otherwise, the petition for writ of certiorari will fail.
A lis pendens has legal significance. It is a recorded document that notifies the world that there is a pending lawsuit dealing with the real property at issue. This is important because who wants to buy a piece of property that is subject to litigation – that would be a risky transaction!
In CPPB, LLC v. Taurus Apopka City Center, LLC, 48 Fla.L.Weekly D1837a (Fla. 6th DCA 2023), a dispute arose as to a real estate transaction. The owner sold a parcel to a buyer. The owner also owned three adjacent parcels. As part of the transaction, the buyer agreed to perform certain improvements to all of the parcels including those adjacent parcels owned by the owner. The owner deposited funds in escrow for purposes of its share of the improvements. A payment dispute arose regarding the improvements and the buyer sued the seller. The seller filed a counterclaim to rescind the transaction along with a recorded lis pendens on the parcel purchased by the buyer. The buyer moved to dissolve the lis pendens which the trial court denied. This prompted the appeal – a petition for a write of certiorari based on the trial court’s denial of the motion to dissolve the lis pendens.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
9th Circuit Plumbs Through the Federal and State False Claims Acts
January 16, 2024 —
Garret Murai - California Construction Law BlogYou may have heard of the False Claims Act and know that it penalizes companies and individuals in contract with the government who present false claims. The federal False Claims Act was signed into law by President Abraham Lincoln in 1863 to penalize profiteers during the Civil War who were selling the Union Army moth eaten blankets, boxes of sawdust instead of guns, and sometimes re-selling the Army calvary horses several times over. Since then, many states, including California, as well as municipalities, have enacted their own false claim statutes.
As currently written, the federal False Claims Act provides for statutory penalties against any person who:
- “[K]nowingly presents, or causes to be presented, a false or fraudulent claim for payment or approval”;
- “[K]nowingly makes, uses or causes to be made or used, a false record or statement material to a false or fraudulent claim”;
- “[H]as possession, custody, or control of property or money used, or to be used, by the Government an knowingly delivers, or causes to be delivered, less than all of that money or property”;
Read the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Congratulations to San Diego Partner Alex Giannetto and Senior Associate Michael Ibach on Settling a Case 3 Weeks Into a 5-Week Trial!
April 15, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPPartner Alex Giannetto and Senior Associate Michael Ibach of BWB&O’s San Diego office started a trial in San Diego set to last at least five weeks. Plaintiffs alleged causes of action of negligence, trespass and nuisance against BWB&O’s client, arguing the owner/property manager did not properly handle alleged overwatering of the front yard, allegedly resulting in a landslide impacting 8 homes on a City slope in Carlsbad. Cross-Complainant City alleged independent negligence to fix the slope it owned and controlled as well as various indemnity-based causes of action against BWB&O’s client. Plaintiffs claimed over $24 million in damages, while Cross-Complainant placed sole blame for the incident on BWB&O’s client around $6 million.
Heading into trial, it was made clear that neither Plaintiffs nor Cross-Complainant would accept anything less than 7-figures to settle BWB&O’s client out of the case. In the first week of trial, BWB&O was able to leverage motions in limine, opening statements, and cross-examinations to secure a dismissal of three of the four causes of action alleged by Plaintiff that were associated with pain & suffering. In the second week of trial, BWB&O secured a dismissal of Cross-Complainant’s negligence cause of action paving the way for a settlement with Plaintiffs. Leveraging the threat of a non-suit when Plaintiffs rested, BWB&O secured resolution of Plaintiffs’ complaint for a fraction of what had previously been sought. Finally, BWB&O was able to secure a dismissal of the remaining indemnity-based causes of action in the cross-complaint and fully extract the client from the matter.
Read the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Specification Challenge; Excusable Delay; Type I Differing Site Condition; Superior Knowledge
January 02, 2024 —
David Adelstein - Florida Construction Legal UpdatesAn Armed Services Board of Contract Appeals dispute, Appeal of L.S. Black-Loeffel Civil Constructors JV, ASBCA No. 62402, 2023 WL 5827241 (ASBCA 2023), involved which party bore liability for delay—the federal government or the prime contractor–based on various legal theories. Without detailing the factual details, a number of interesting legal issues were raised in this dispute including (1) a defective specification challenge, (2) excusable delay, (3) Type I differing site condition, and (4) superior knowledge. These legal issues are discussed below.
1. Specification Challenge (Defective Specifications)
The contractor claimed that the government’s specifications were defective in regard to a thermal control plan. The government countered that the specifications were not design specifications but performance specifications. The specifications were performance based because they did not tell the contractor how to achieve the performance-based criteria.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Kahana Feld Welcomes Six Attorneys to the Firm in Q4 of 2023
January 16, 2024 —
Linda Carter - Kahana FeldKahana Feld is pleased to announce the addition of six attorneys to the team in the fourth quarter of 2023. We are excited to have each of these individuals on the team.
In our Houston office, Kahana Feld welcomes Partner Donald Loving II and Attorney Elliott Wright. Mr. Loving is a member of the General Liability and Trucking & Transportation practice groups. He earned his Juris Doctor from the University of Houston and has over 30 years of litigation and trial experience, including working as staff & corporate counsel for several prominent insurance carriers including GEICO, Progressive, USAA and Travelers. Mr. Wright is a member of the Construction Defect, General Liability, and Trucking & Transportation practice groups. He earned his Juris Doctor from SMU Dedman School of Law, and has extensive litigation and insurance defense experience.
Read the full story...Reprinted courtesy of
Linda Carter, Kahana FeldMs. Carter may be contacted at
lcarter@kahanafeld.com
Sweat the Small Stuff – Don’t Overlook These Three (3) Clauses When Negotiating Your Construction Contract
April 08, 2024 —
Bill Shaughnessy - ConsensusDocsReviewing and understanding the terms of your construction contract before signing on the dotted line (ideally with counsel involved) is an obvious best practice – whether you are owner, general contractor, design-professional or down-tier subcontractor or supplier. Typically, during this review process, parties pay closest attention to terms relating to price, scope, schedule, insurance, indemnification, and damages. And rightfully so, as these are just some of the most fundamental and important clauses of any construction contract.
But during this review and understanding process, parties often overlook and fail to fully review and understand several notably important contract provisions (other than the examples above) which can have just as significant an impact on the project and even unintended consequences once construction starts. This article discusses three (3) of these often-overlooked provisions which should also be carefully reviewed to ensure the project runs smoothly and to avoid unintended consequences or even disputes (and litigation) during construction:
- Incorporation by reference clause;
- Order of precedence or higher standard clause; and
- Choice of law clause.
Read the full story...Reprinted courtesy of
Bill Shaughnessy, Jones Walker LLP (ConsensusDocs)Mr. Shaughnessy may be contacted at
bshaughnessy@joneswalker.com
Reasonable Expectations – Pennsylvania’s Case by Case Approach to the Sutton Rule
February 12, 2024 —
Melissa Kenney - The Subrogation StrategistIn Mutual Benefit Ins. Co. a/s/o Michael Sacks v. Koser, No. 1340 MDA 2023, 2023 Pa. Super. LEXIS 574, 2023 PA Super 252 (Mutual Benefit), the Superior Court of Pennsylvania discussed whether a landlord’s property insurer could file a subrogation action against tenants that had negligently damaged the landlord’s property. Despite there being more than one clause in the lease holding the tenants liable for the damages, the court held that because there was a provision requiring the landlord, not the tenants, to insure the leased building, the insurer could not subrogate against the tenants.
In Pennsylvania, a tenant’s liability for damage to a leased premises in a subrogation action brought by a landlord’s insurer is determined by the reasonable expectation of the parties to the lease agreement. Under this approach, to determine if subrogation is permitted, the court considers the circumstances of the case and examines the terms of the lease agreement.
In Mutual Benefit, the tenants leased and resided in a residential home pursuant to a lease agreement. The lease specifically addressed insurance, stating that landlord was responsible for obtaining insurance on the dwelling and the landlord’s personal property, and tenants were encouraged to procure separate insurance for their personal property. The lease also addressed liability for damage to the leased property, stating generally that the tenants were responsible for damage caused by the tenants’ negligence.
Read the full story...Reprinted courtesy of
Melissa Kenney, White and WilliamsMs. Kenney may be contacted at
kenneyme@whiteandwilliams.com
Unpunished Racist Taunts: A Pennsylvania Harassment Case With No True 'Winner'
December 04, 2023 —
Richard Korman - Engineering News-RecordThe taunts started in the first days of Andre Pryce’s new job, camouflaged as joking. During the nine months of 2019 spent working as a drill rig hand, mostly in the woods in western Pennsylvania, for a contractor that also performs much construction-related drilling, he said coworkers filled his ears with racist insults.
Reprinted courtesy of
Richard Korman, Engineering News-Record
Mr. Korman may be contacted at kormanr@enr.com
Read the full story...